英文合同

关于英文合同集合八篇

　　随着法律知识的普及，合同的法律效力与日俱增，签订合同可以明确双方当事人的权利和义务。相信很多朋友都对拟合同感到非常苦恼吧，以下是小编为大家收集的英文合同8篇，仅供参考，希望能够帮助到大家。

英文合同 篇1

　　CONTRACT OF ATTORNEY FOR LAWSUIT

　　甲方： Party A:

　　地址：Address:

　　电话： Telephone:

　　乙方：Party B:

　　地址：Address:

　　电话：Telephone No.:

　　根据《中华人民共和国律师法》以及其他相关法律法规的规定，甲乙双方同意以下条款：

　　According to ATTORNEY LAW OF THE PEOPLE’S REPUBLIC OF CHINA, and other relevant laws and regulations of P.R.China, Party A and Party B mutually agree to the following terms:

　　一、委托事项

　　commitment

　　（1）甲方与W电讯有限公司之间诉讼案的二审或者申诉和判决后的执行；

　　A. The second instance, or appeal of the litigation between Party A and W company.

　　（2）所有与（1）条相关的诉讼、仲裁、上诉、执行程序直到终审和判决执行，包括判决金额的取得。

　　B. Other litigation, arbitration, appeals, enforcements and/or all proceedins relevant to the actions listed in Exhibit A until final judgment and enforcement of judgement, including collection of judgment amount is finalized.

　　（3）在合理范围内,诉讼和仲裁的策略最终决定，以及任何相关的诉讼事实，决定权在甲方。在本协议有效期,乙方将尊重甲方的指示，除非该指示违反中国的法律。

　　C.Within reason, the final decision regarding strategy of litigation and/or arbitration, as well as any and all facts of the litigation, are at the full discretion of Party A. Pursuant to the terms of this Agreement, Party B shall follow the

　　instructions of Party A unless these instructions violate the law in the People’s Republic of China.

　　二、代理费用及支付方式

　　2. Payment of Fees

　　2.1代理费用。乙方根据本协议完成全部代理工作的代理费用由如下两部分组成： 固定费用：人民币15万元整（含税）,作为乙方律师工作成本费用。在本协议签订后5日内一次性电汇至乙方指定帐户；乙方出具发票。另行提成费用：乙方将根据本协议从本案最终执行回来的全部净收益中提取40%。净收益的含义如下：来自本案的全部金额，减去已经支付的案件费用。甲方扣除费用指的是从法院执行回款中扣除本案一审和二审的诉讼费以及法院执行费。

　　如果执行回的净收益少于已经支付的费用，双方按照如下分配：每一方都按照收益的比例分配。比如,诉请金额为人民币100元，收益为10元，即收益为诉请的10%。乙方将得到收益金额的40%。

　　2.1 Party B’s fees for all services under this Agreement shall be paid in two separate installments:

　　A. Fixed fee: RMB 150,000(before tax) to be paid in one installment within 5 days of the signing of this Agreement by wire as designated by Party B and upon receipt from Party B; The fixed fee is the work cost of attorney for fulfilling the commitment.

　　B. Party B shall be paid 40% of all Net Proceeds collected from enforcement of judgments resulting from cases under this Agreement. Net Proceeds is defined as follows:Total amount collected amount in case, less case filing fee of court’s first and second instances or arbitration.

　　Where the collected Net Proceeds are less than the Paid Amounts, the parties shall apportion the Net Proceeds as follows: Each Party shall be paid the pro rata share of the collected amounts vs. the collected amounts. Thus, if the claimed amount is $100 rmb, and the collected amount was $10 rmb, this represents 10% of the claimed amount. Thus Party B shall receive 40% of the collected amount, less 10% of the collected amount.

　　2.4 支付方式Payment

　　固定费用的支付方式： Payment of fixed fee:

　　本协议签定后5个工作日内支付固定费用。

　　the fixed fee shall be paid within 5 business days after the signing of this agreement. 提成费用支付方式：Payment of royalty:

　　甲方在收到资金后7个工作日支付。

　　royalty fee shall be paid within 7 business days of receipt of funds by Party A’s.

　　2.5 乙方收款帐户 Bank account of Party B

　　收款单位:Name of Account:

　　开户银行:Bank of Account:

　　帐号:Account No.

　　三、甲方权利和义务 Rights and obligations of Party A

　　3.1如果发生如下情况:实际情况不允许履行、公司终止，与乙方发生无法协调的分歧，甲方可以根据自己的决定终止本协议，应在5个工作日内书面通知乙方。已付给乙方的费用不再要求退还。

　　3.1 Party A, may, at its discretion, terminate this Agreement, or any portion thereof for reasons of impracticality, company wind down, or irreconcilable differences with Party B, upon 5 business days written notice to Party B; but don’t require Party B to hand back the payment paid to Party B .

　　3.2甲方在行使终止权利时，如果乙方代理的具体案件已经进入执行阶段，且有充分证据表明本案判决或者仲裁的.执行收益可以成功执行的，除非乙方书面同意，甲方不能终止该案件的委托。

　　3.2 While Party A is executing his right of termination, if a special commitment is in enforcement stage and there are plenty evidences to indicate that the judgment or

　　the arbitration award of the case will be successfully executed, Party A can not terminate this special commitment without Party B’s written consent.

　　3.3 甲方将全力在尽早的时间内向乙方提供案件文件。

　　3.3 Party A shall use all reasonable efforts to provide Pary B with the case files at the earliest practicable time;

　　3.4 为了使乙方按照本协议履行职责,甲方将全力提供乙方所要求的文件和其他支持性文件,并指定专人作为甲方与乙方的联系人，给予相应的联系方式。

　　3.4 Party A shall make every reasonable effort to provide Party B with requested documentation or other support documents in order for Party B to discharge its duties under this Agreement; A person specially will be assigned by Party A for the linkman with Party B, and give party B relevant contact manner.

　　四、乙方权利 Rights of Party B

　　4.1 乙方有按照法律和合同的约定独立完成约定工作的权利,不受甲方不适当的干预。

　　4.1 Party B is entitled to perform the stipulated work according to laws and regulations as well as this Agreement without undue interference from Party A;.

　　4.2 乙方在按约定完成工作后，有获得约定费用的权利。

　　4.2 Party B has the right to be paid after he finishes stipulated work.

　　4.3 乙方如发现以下情况，可及时书面通知甲方，提出解决办法，直至终止本协议：

　　（1）甲方没有按照乙方合理的要求提供实际有的和能够取得的支持性文件；

　　（2）甲方提供的支持性文件和证据是虚假的或者不准确，使乙方不能够按照本协议履行职责。

　　（3）由于甲方不合理的干预，双方产生无法协调的分歧。

　　4.3 If Party B find the following facts, should notice in written to Party A and put forward settle means, until terminate this Agreement:

　　甲方（签章）：_________ 乙方（签章）：__________________年____月____日 _________年____月____日

英文合同 篇2

　　买 方： (The ;Buyers)

　　卖方： (The Sellers)

　　兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：

　　This contract is made by and between the Buyers and the Sellers; whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter:

　　(1) 商品名称:

　　Name of Commodity：

　　(2) 数 量： Quantity:

　　(3) 单 价： Unit price:

　　(4) 总 值： Total Value:

　　(5) 包 装： Packing:

　　(6) 生产国别： Country of Origin :

　　(7) 支付条款： Terms of Payment:

　　(8) 保 险： insurance:

　　(9) 装运期限： Time of Shipment:

　　(10) 起 运 港： Port of Lading:

　　(11) 目 的 港： Port of Destination:

　　(12)索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不附，除属保险公司或船方责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。

　　Claims:

　　Within 45 days after the arrival of the goods at the destination, should the quality, Specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable, the Buyers shall, have the right on the strength of the inspection certificate issued by the C.C.I.C and the relative documents to claim for compensation to the Sellers

　　(13)不可抗力：由于人力不可抗力的原由发生在制造，装载或运输的过程中导致卖方延期交货或不能交货者，卖方可免除责任,在不可抗力发生后，卖方须立即电告买方及在14天内以空邮方式向买方提供事故发生的证明文件，在上述情况下，卖方仍须负责采取措施尽快发货。

　　Force Majeure :

　　The sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers immediately of the occurrence mentioned above the within fourteen days there after . the Sellers shall send by airmail to the Buyers for their acceptancea certificate of the accident. Under such circumstances the Sellers, however, are still under the obligation to take all necessary measures to hasten the deliveryof the goods.

　　(14）仲裁：凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提交中国国际贸易促进委员会按有关仲裁程序进行仲裁，仲裁将是终局的，双方均受其约束，仲裁费用由败诉方承担。

　　Arbitration :

　　All disputes in connection with the execution of this Contract shall be settled friendly through negotiation. in case no settlement can be reached, the case then may be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Procedure promulgated by the said Arbitration Commission . the Arbitration committee shall be final and binding upon both parties. and the Arbitration fee shall be borne by the losing parties.

　　买方： 卖方:

　　（授权签字） （授权签字）

　　【拓展延伸】

　　1.前言 Preamble

　　一份标准英文合同通常可以分为前言（Preamble）、正文（Operative part）、附录（Schedule）及证明部分即结束词（Attestation）四大部分组成。

　　前言（Preamble）由“Parties”及“Recitals”两部分组成。

　　“Parties”为必备条款，在很多时候称为“commencement”即合同的开场白，主要介绍合同各方的名称或姓名、注册地及地址、邮编及在合同中的简称。当然，并不是所有的合同都要详细介绍以上诸要素，在许多简单合同中，只是提一下各方的名称。

　　I. 以下为“Parties”的常用表达方式：

　　1. This Agreement is entered into by and between ____ and ____.

　　本协议由以下双方____和___ 签署。

　　2. This Agreement is entered into by and between ____ (hereinafter referred to as____) and ____ (hereinafter referred to as "_____"), whereby it is agreed as follows:

　　本协议由以下双方____（以下简称____）和_____（以下简称___）签署，达成如下协议：

　　注：在很多合同中，这部分加入签约事由，如：

　　This Agreement is entered into through friendly negotiations between _____ Co.

　　(hereinafter referred to as the “Party A”) and _____ Co. (hereinafter referred to as the “Party B”) based on equality and mutual benefit to develop business on the terms and conditions set forth below:

　　本协议由_____（以下称为甲方）和____（以下称为乙方）为发展业务在平等互利的基础上签订，其条款如下：

　　This Agreement is entered into between _____ (hereinafter referred to as "Company"), and ______, (hereinafter referred to as "Employee") pursuant to paragraph VIII(2) of the Employee Handbook, whereby it is agreed as follows:

　　本“协议”由_____（以下简称“公司”）与_____（以下简称“雇员”）根据“雇员手册”第VIII(2)款签署，“协议”内容如下：

　　II. 以下为标准的“Parties”条款：

　　3. This Agreement is made and entered into this _____th day of _____ in the year of ____ by and between ______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at _____ (hereinafter referred to as “_____”), and ______, a company duly organized and existing under and by virtue of the laws of _____, with its principal place of business at _____ (hereinafter referred to as “_____”), whereby it is agreed as follows:

　　本合约由______，在_____法律之下并凭该等法律正式组织并存在的公司，其主要营业地点在______（下称_____），与_____，在_____法律之下并凭该等法律正式组织并存在的公司，其主要营业地点______（下称代理人），于_____日签订和缔结，协议如下：

　　III. “Recitals” 由数个以"Whereas"字样开头的句子所组合而成（这些句子俗称为“Whereas Clauses”），表示当事人乃是在基于对这些事实（例如订约的目的、背景来由等）的共同认识，订立此合约。

　　4. This Agreement is made and entered into this _____ day of _____ in the year of ____ by and between _______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at ______ (hereinafter referred to as “_____”), and ______, a company duly organized and existing under and by virtue of the laws of ______, with its principal place of business at ______ (hereinafter referred

　　to as “_____”)

　　WITNESSED

　　WHEREAS, NOW THEREFORE, the parties hereto agree as follows:

　　本合约由_____，在_____法律之下并凭该等法律正式组织并存在的公司，其主要营业地点在______（下称_____）（或下称供应商），与_______，在_____法律之下并凭该等法律正式组织并存在的公司，其主要营业地点_

　　鉴于

　　因此，双方当事人达成以下协议：

　　注：WITNESSED可以用WITHNESSTH、WITHNESSTH THAT等来代替。

　　IV. 在很多美国常用合同中，在很多情况下直接用RECITALS引导数个陈述语句或“Whereas Clauses”。下面为一个资产购买协议实例：

　　This ASSET PURCHASE AGREEMENT (the "Agreement") is made and entered into as of May 19, 1997 by and among AAA, a Delaware corporation ("AAA"), BBB, a Delaware corporation and wholly-owned subsidiary of AAA ("Buyer"), CCC ("Summit"), and DDD, an Oregon corporation and wholly-owned subsidiary of Summit ("Seller").

　　RECITALS

　　A. The Boards of Directors of each of Summit, Seller, AAA and Buyer believe it is in the best interests of each company and their respective security holders that Buyer acquire certain listed assets and assume certain listed liabilities of Seller (the "Acquisition").

　　B. On the date hereof, Buyer has executed a $2,000,000 irrevocable purchase order to purchase 400 time-based licenses for Summit's Visual HDL interfaces for Visual Test bench ("VTB") software on AAA's standard form of purchase order, which is payable within five (5) business days after the date hereof.

　　NOW, THEREFORE, in consideration of the covenants, promises and representations set forth herein, and for other good and valuable consideration, the parties agree as follows:

　　2. 定义 Definition

　　在正文（Habendum）部分，通常第一章为定义（Definitions）部分。

　　定义条款即对合同中涉及的术语及名词作出限定、解释的条款。它可以散见于合同各个部分，但对于一些大型的、重要的合同，通常将其置于第一章。

　　I. 常见的定义语句常用mean, refer to, be construed as, include等来表达。如：

　　1. "Territory" means the United States of America.“销售地区”是指美利坚合众国。

　　2. “Commencement date” shall mean the date of signing this agreement by the last signing party hereto.

　　“协议生效日”是指本“协议”最后签字的一方签署本“协议”的日期。

　　3. The “agreement” herein referred to shall mean this agreement of agency by entrustment.

　　“协议”在这里是指本委托代理协议。

　　4. “Code” shall refer to the current and applicable Internal Revenue Code.

　　“法”是指当前可用的国内税收法。

　　5. Reference to any statutory provision shall be construed as a reference to the same as it may have been, or may from time be, amended, modified or re-enacted.

　　引用法律规定理解为引用其本身外，还包括其修订、修正或重新实施案。

　　6. "Expenses" include costs, charges and expenses of every description.

　　“费用”包括各种形式的金钱支出。

　　II. 还有一类特殊的定义语句，即对于「单、复数」及「阴、阳性」名词的范围定义。通常都是用include来表达：

　　1. "Stock Certificate" includes "stock certificate" and "stock certificates".

　　合同中的“股票”，包括单数与复数。

　　2. "He" includes "he" and "she".

　　合同中的“他”，包括“他”与“她”。

　　3. Words using the singular or plural number also include the plural or singular number.

　　采用单数或复数的单词也包括复数或单数。

　　III. 定义语句中，有时需限定范围。而通常用得最多的是：“for the purpose of ”及“in relation to” 某概念的定义条款，如果适用范围仅限于合同的“特定部份”，可以用“for the purpose of ”来为定义条款起头。而如果定义条款是针对合同的“特定概念”，就用“in relation to”来界定。如下例：

　　1. For the purpose of this Agreement, "Products" means all types of the machineries manufactured by Manufacturer as are specified in Attachment A hereto.

　　本协议所称的“产品”，指制造人所制造如附件A表列之各式机器。

　　2. "Address" means－

　　(a) 就自然人而言in relation to an individual, his usual residential or business address; and

　　(b) in relation to a corporation, its registered or principal office in the Republic of China.

　　“地址”就自然人而言，指通常之居所或工作场所；就公司而言，指位于中华人民共和国之注册所在地或主营业所。

　　IV. 在定义条款中，在定义语句前有时会加上一些陈述语句来引导，如：

　　1. For the purpose of this Agreement, each of the following terms shall have the following meaning respectively:

　　就本合同的目的而言，下列各用语，分别具有下述意义：

　　2. In this Agreement, the following words or expressions shall have the meanings given to them respectively below:

　　本协议内所用词句的意义，明确阐述如下：

　　3. In this agreement unless the context otherwise requires, the following words and expressions shall have the meanings assigned to them hereunder:

　　除非本“协议”有明确规定，下列词语应当具有如下规定之意义：

　　4. The following are the definitions of various terms used in this Agreement:

　　本“协议”使用之术语定义如下：

　　3. 有效期 Period of validity

　　有效期(Term)条款通常规定合同的有效期限，何时生效及到何时结束，合同结束后必要时如何延展等等。

　　I. 以下为“Term”的常用表达方式：

　　The term of this contract is for a _____ year period.合同的有效期为_____年。

　　如：The term of this contract is for a one (1) year period.

　　2. The contract is for a _____ month period, commencing _____.

　　合同的有效期为_____月，开始于______。（期限）

　　a. The contract is for a 12 month period, commencing September 17, 20xx thru September 16, 20xx.

　　b. The contract is for a 6 month period, commencing 4-1-03 and ending 9-30-20xx.

　　3. This agreement remains valid for _____ year(s), i.e. commencing on ______, _____and terminating on ______, _____.

　　本协议在_____年之内有效，即从_____年_____月_____日起生效，_____年_____月_____日起到期。

　　4. The contract term is hereby extended for the period____.

　　合同的有效期为_______。

　　如：The contract term is hereby extended for the period____ in accordance with Section E, Paragraph 10, Term of Contract and Contract Extension.

　　II. Term条款除了规定合同的期限外，通常另外合同期限的延展“Extension”。

　　1. The contract period is for _____ year with option to re-new for _____ year.

　　合同有效期为_____年，同时可以选择延长_____年。

　　2. The contract is for a _____ month period, commencing _____. The contract may be renewed for up to _____ year option periods.

　　合同的有效期为_____月，开始于_______，同时可以选择延长_____年。

　　3. This agreement shall commence on the commencement date and shall endure for a continuous period of _____ years. Thereafter it will be automatically renewed for successive periods of _____ years on the same terms and conditions unless one of the parties had given _____days notice of termination.

　　本协议应自生效日生效并在_____年内有效。此后，除非一方当事人提前_____天书面通知对方当事人终止本协议，本协议有效期自动延长_____年，协议条款不变。

　　III. Term条款并没有十分固定的表达方式，以下即是一些合同中Term的实例：

　　1. This Agreement shall be valid and remain in force for a period of three (3) years commencing from the date appearing first above written upon the signing of both Party A and Party B and shall be extended for another period of three (3) years on the same terms and conditions unless either of the parties hereto gives the other party at least thirty (30) days prior written notice to terminate this Agreement prior to the expiration of the original term.

　　本合约须从上面首次写明的甲方和乙方签订本约的日期起生效并保持效力三年，并将按同样条件延长三年，否则与约任何一方至少须在原定时间期满前三十天给予另一方提前终止本合约的书面通知。

　　2. At any time and from time to time during the period commencing on the date hereof and terminating on ______, 20___, party A may in writing advise party B.

　　自本协议签订之日起到______年______月协议终止这段期间内，甲方可随时以书面形式通知乙方。

　　3. The term of this Agreement shall be three years from the effective date, unless terminated in accordance with Article VI- (3) and Article IX.

　　本合同的期限除非根据第8条第3款及第9条的规定终止外，有效期为3年。

　　4. The contract is valid from _______ until _______.

　　The contract period is automatically extended for any leave of absence allowed for in law.

　　合同的有效期为从______到_____。

　　5. The term of this Agreement shall commence on the _____ day of _____ and end on the _____ day of _____ Upon expiration of the above initial term, this Agreement shall automatically be renew and extended for a like period of time unless terminated in writing by either party _____ days prior to the date for such renewal.

　　本协议期限为__年____月____日至__年___月___日。除非续订日前_____天一方以书面方式提出终止，否则上述首期届满后，协议应自动续订，延长时间与前期相同。

　　4. 不可抗力 Force Majeure

　　Force Majeure条款是一种免责条款，即免除由于不可抗力事件而违约的一方的违约责任。一般应规定的内容包括：不可抗力事件的定义（Definition of Force Majeure）以及不可抗力事件的后果（Consequences of Force Majeure） 。在Force Majeure条款中，两者属于因果关系，难以截然分开。

　　I. 对于Force Majeure的定义，《合同法》定义如下：

　　本法所称不可抗力，是指不能预见、不能避免并不能克服的客观情况。

　　For purposes of this Law, force majeure means any objective circumstance, which is unforeseeable, unavoidable and insurmountable.

　　II. 以下是Force Majeure条款的举例：

　　1. Neither party shall be responsible for delays or failures in performance resulting from acts or facts reasonably beyond the control of that party.

　　任何一方不应对因其无法控制之行为或事实造成协议延迟履行或不履行承担任何责任。

　　2. Either Party shall not be liable for any delay caused by any unpredictable factor or any factor which is unavoidable or insurmountable by reasonable means at the time of conclusion of this Agreement, or any loss caused by failure in fulfillment of obligations as stipulated herein.

　　协议任一方无须对因任何在本协议签订时无法预见或以合理手段也无法避免或克服之原因造成的迟延或不履行本协议之义务所造成的损失承担责任。

　　注：以上采用的是类似《合同法》概括的定义方法。而合同为不可抗力定义时更多地采用列举的方法。

　　3. Neither party of this Agreement, directly or indirectly owing to any causes or circumstances beyond its control, including Acts of God, Governmental orders or restriction, war, warlike conditions, revolutions, strike, lockout, fire and flood.

　　本合同任何一方当事人对直接或间接地由于其无法控制的原因或情况包括自然灾害、政府命令或限制、战争、战争状态、革命、罢工、工厂被关闭、火灾、水灾等而未能履行或延迟履行合同或合同一部分的行为，不负任何责任。

　　注: Acts of God通常也译为“不可抗力”，但主要是指自然灾害；而Force Majeure则包括自然及人为两方面。

　　4. Neither party will be liable for nondelivery, misdelivery or late delivery (other than the payment of money due hereunder) caused by circumstances beyond its reasonable control, including, among others, war, civil strife or commotion, riots, strikes, fires, floods, acts of God, inability to obtain materials, failure of carriers or compliance with any law, regulation or governmental order.

　　任何当事人将不会为任何因为不可控制的情况产生的未交付货物、交付错误或延迟交货（除了支付应付款）。不可控制的情况包括战争、国内斗争或*乱、骚乱、罢工、火灾、洪灾、自然灾害、无力获得材料、承运人的失误、遵守法律、法规或政府令。

　　5. Should either of the parties to the contract by prevented from executing the contract by force majeure, such as earthquake, typhoon, flood, fire and war and other unforeseen events, and their happening and consequences are unpreventable and unavoidable, the prevented party shall notify the other party by cable without any delay, and within 15 days thereafter provide the detailed information of the events and a valid document for evidence issued by the relevant public notary organization

　　for explaining the reason of its inability to execute or delay the execution of all or part of the contract. Both parties shall, through consolations, decide whether to terminate the contract or to exempt the part of obligations for implementation of the contract or whether to delay the execution of the contract according to the effects of the events on the performance of the contract.

　　由 于地震、台风、水灾、火灾、战争以及其它不能预见并且对其发生和后果不能防止或避免的不可抗力事件出现，致使直接影响合同的履行或者不能按约定的条件履行 时，遇有上述不可抗力的一方，应立即电报通知对方，并应在十五天内，提供不可抗力详情及合同不能履行、或者部分不履行、或者需要延期履行的理由的有效证明 文件。此项证明文件应由事故发生地有权证明的机构出具。按其对履行合同影响的程度，由双方协商决定是否解除合同，或者部分履行合同，或者延期履行合同。

　　6. Force majeure shall hereof consist of the following events:

　　下述事件构成不可抗力：

　　Where such cases as war, earthquake, serious windstorms, snow, or fire or other events which no party can foresee and prevent from happening occur;

　　发生战争、地震、严重的风灾、雪灾、火灾或其他各方无法预见、无法抗拒的事故。

　　The related laws and regulations in collection with the execution of duties by any party to this Agreement undergo changes, under which this Agreement will be illegal or the transfer cannot be fulfilled.

　　自本协议签订之日起与本协议任何一方履行本协议相关的法律、法规发生变更致使本协议非法或转让行为无法完成。

　　In event of the occurrence of the above-mentioned events, if any party (hereinafter referred to as the “Effected Party ”) has been delayed or deterred from performing the duties of this Agreement in the course of its execution, the Affected Party shall be free from any liabilities for breach of the agreement and for compensation.

　　在发生本协议不可抗力事件之后，任何一方（以下简称受影响方）在履行本协议义务时受到拖延或不能履行时，受影响方不承担任何违约责任及赔偿责任。

　　In event of the force majeure, the affected party shall, within _____days from the date of the occurrence, notify the other party of the impact of such events on the execution of the duties in this Agreement, by telex, telegraph or in any other lawful written form, and simultaneously submit the relevant official credentials concerning the force majeure herein.

　　在发生不可抗力事件时，受影响方应自不可抗力事件发生之日起_____天内以电传或电报或其他任何合理书面方式，通知另一方有关不可抗力的发生和不可抗力对其履行本协议的义务的影响，同时应呈交不可抗力的有关官方证明。

　　Should the effect of the force majeure cases last more than _____ days, both parties shall consult each other about the alterations of this Agreement; in case they fail to reach an agreement, Chapter 8 shall thereupon apply.

　　在不可抗力事件延续_____天后，双方必须磋商本协议的变更，双方未能协商一致的，适用本协议第八章的规定。

　　7. Force Majeure不可抗力

　　(1) No party to this Contract shall be liable to the other party for any failure of or delay in performance of its obligations hereof nor be deemed to be in breach of this Contract, if such failure or delay has arisen from "force majeure."

　　如果任何一方因不可抗力而款能履行或推迟履行其义务，则不对另一方负责，也不应视作违反合同。

　　"Force Majeure" means circumstances and conditions beyond the control of either parties, that would render it impossible for either the Owner or the Contractor to fulfill their obligations under this Contract, or delay such fulfillment. Any of the following matters are considered "force majeure."

　　“不可抗力”指业主或承包商无法控制的情况，使当事人未能按本合同履行其义务，或者不得不延迟履行其义务。下列情况均被视作“不可抗力”：

　　a. war, hostilities, act of foreign enemy, invasion, warlike opera-tions (whether war to be declared or not) or civil war;

　　b. mutiny, civil commotion assuming the proportions of or amounting to a popular rising, military rising, insurrection, rebellion, revolution, military or usurped power, or any act of any person acting on behalf of or in connection with any organization with activities directed towards the overthrow by force of the Government de jure or de facto, or to the influencing of it by terrorism or violence;

　　c. earthquake, flood, fire or other natural physical disaster;

　　d. denial of the use of all ports, airports, shipping services or other means of public transport;

　　e. strike or lock out or other industrial concerted action by workers, affecting the fulfillment of Contractor's and subcontractors' obligations;

　　f. and other unforeseen circumstances beyond the control of the parties so affected rendering the fulfillment of their obligations impossible.

　　a. 战争、敌对事件、外敌行动、入侵、类似战争的军事行动（不管是事宣战）、内战；

　　b. 士兵哗变、民众*乱、军事叛乱、起义、造反、革命、篡权、或者任何个人代表某个组织或与某个组织有联系、旨在以暴力推翻合法或现存政府、或以恐怖主义或暴力对政府施加影响的行为；

　　c. 地震、洪水、火灾或其他自然灾害；

　　d. 所有港口、机场、船运或其他公共交通工具的使用均遭拒绝；

　　e. 工人罢工、工厂停工、或其他的劳工联合行动，影响了承包商和分包商履行其义务；

　　f. 当事人无法控制、从而使其不能履行义务的其他任何意外情况。

　　(3) If either party to this Contract is prevented or delayed from or in performing any of his obligations under this Contract by force majeure, then he may notify the other party of the circumstances constituting the force majeure and of the obligation performance of which is thereby delayed or prevented and the party giving the notice shall thereupon be excused from the performance or punctual performance, as the case may be, of such obligation for so long as the circumstances of prevention or delay may continue.

　　如果本合同任何一方因不可抗力不能或延迟履行本合同规定的任何义务，他可将不可抗力和由此造成的延迟或妨碍情况通知另一方。发出通知的一方允许根据具体情况及妨碍或延迟持续的时间免于履行或推迟履行合同。

　　(4) If by virtue of the preceding sub-clause dither party shall be excused from the performance or punctual performance of any obligation for a continuous period of ________ months, then either party may at any time thereafter terminate this Contract by giving a written notice to the other party.

　　根据本第款第3分条规定，如果任何一方免于履行或推迟履行其义务的时间持续了____个月，那么任何一方都可随时向另一方发出书面通知，终止本合同。

　　5. 修改 Modification

　　合同修订 (Modification)条款为合同常用条款.主要规定了合同修订的方式与途径。例如：书面合同，只能以书面方式进行修订，口头修订内容无效。

　　I. Modification条款通常较为简单，以下为一些常用比较简约的表达方式：

　　1. The contract can be amended only after the amendment is agreed upon by both parties.

　　只有经双方一致同意，合同方可变更。

　　2. This Agreement may be amended only by a written instrument signed by duly authorized representatives of both parties.

　　本合同只有经双方当事人授权的代表正式签署的书面文件，方可修改。

　　3. This Agreement may not be amended or modified except by written instrument signed

　　by each of the Parties hereto.

　　除非经本协议当事人签署的书面通知，否则本协议书不得作出任何修改和变更。

　　4. Any alterations or amendments of this Agreement shall be subject to agreement through consultation between both parties in writing.

　　本协议的任何变更或修改，应由本协议双方协商一致，并以书面方式进行。

　　5. This Agreement shall not be modified or amended except by a written instrument, signed by the parties hereto.

　　除非双方当事人共同签署书面文件，否则本“协议”不得修改或修订。

　　6. Any modification, amendment or waiver of any of the provisions of this Agreement must otherwise be made in writing and duly signed by the parties hereto.

　　对本“协议”任何规定的任何变更、修改或免责必须另以书面形式作出，并经各方正式签字。

　　7. During the period of validity of the agreement, either party shall be entitled to make proposal of amendment to the agreement and the agreement amended shall go into effect with the signature of the two parties.

　　在协议的有效期内，任何一方都有权提出对协议进行修改，修改后的协议经过双方签署后才能够生效。

　　II. 在实际运用中，由于内容环境不同，表达可能有所不同，以下为一些实例：

　　1. If the loan contract affiliated to this Contract has to be abridged, amended, or revised, both parties shall negotiate to amend and revise this Contract in line with the provisions of the loan contract.

　　本股权质押项下的贷款合同如有修改、补充而影响本质押合同时，双方应协商修改、补充本质押合同，使其与股权质押项下贷款合同规定相一致。

　　2. If this Contract shall be abridged, revised, or amended on account of force majeure, the responsibilities assumed by the Party A under this Contract shall not be exempted or reduced, and the rights and interests of the Party B under this Contract shall not been affected or infringed.

　　如因不可抗力原因致本合同须作一定删节、修改、补充时，应不免除或减少甲方在本合同中所承担的责任，不影响或侵犯乙方在本合同项下的权益。

　　3. The amendment of the contract or other appendices shall come into force only after the written agreement signed by Party A and Party B and approved by the original examination and approval authority.

　　对本合同及其附件的修改必须经甲、乙双方签署书面协议，并报原审批机构批准，方可生效。

　　4. This Agreement may be amended in writing signed by both Parties. Unless otherwise expressly agreed to in such amendment, all terms and conditions of this Agreement shall apply to any such addition and all rights granted to Licensee under this Agreement shall terminate as to any such deletion.

　　本协议可由「双方」书面签署予以修改。除在此种修改中另行明确同意外，本协议所有的条款和条件须适用于任何此类修改中所做的添加，而所有根据本协议而给予「被许可人」的权利对于任何此类修改中的删除事项而言将终止。

　　6. 补偿 Indemnification

　　损害赔偿（indemnification）条款，是减少合同风险的一个重要条款。该条款主要约定在第三者对合同提出权利主张时，另一缔约方应当对此承担责任。通常情况下，另一缔约方必须支付全部的防御性诉讼费用，以及全部的支付给第三者的和解费用或者第三者胜诉后造成的所有损失。

　　实际上，本条款是将第三人造成的风险从合同的一方当事人转移给另一方当事人。

　　其次，本条款也可以约定合同的另一缔约方有其他不当的作为时，应当进行损害赔偿。

　　I． Indemnification 条款常用“indemnify and hold harmless from……”来表达：

　　1. Party A agrees to indemnify and hold Party B harmless from any claim or demand, including reasonable attorneys' fees, made by any third party due to or arising out of

　　甲方同意对乙方因_____造成的损失作出赔偿及保证乙方不招致任何第三方索偿或索求，包括合理的律师费用。

　　应用实例：

　　Party A agrees to indemnify and hold Party B harmless from any claim or demand, including reasonable attorneys' fees, made by any third party due to or arising out of Party A's use of the Site, the violation of this Agreement by Party A, or the infringement by Party A, or other user of the Site using Party A's login name and password, of any intellectual property or other right of any person or entity.

　　甲方同意对乙方因甲方使用网站、或甲方违反本协议、或因甲方或其它使用甲方之登记名称及密码而使用网站的使用者，侵犯任何知识产权或任何其它人士或单位的其它权利所造成的损失作出赔偿及保证乙方不招致任何索偿或索求，包括合理的律师费用。

　　2. Party A shall indemnify and hold party B and each of party B officers, directors, stockholders, employees and agents harmless against, and in respect of, any damage, loss, liability, cost or expense, including attorneys, fees, resulting or arising from or incurred in connection with this Agreement and the transactions contemplated hereby, except such as may result from willful malfeasance if party B or such officer, director, stockholder, employee of agent, as the case may be.

　　甲方应当赔偿乙方及其每个职员、董事、股东、雇员及其代理人因此协议引起或与此协议以后的交易相关事项而产生的损害、损失、责任、开支或费用，包括律师费用，但因乙方或其职员、董事、股东、雇员或代理人有意的过失而引起的损失除外。

　　3. Each party will defend, indemnify and hold the other harmless from and against all actions, proceedings, claims, demands, suits, losses, damages and expenses, including reasonable attorneys fees and costs reasonably incurred in defending any proceedings in which the damages sustained arose from a failure of the other party to meet its obligations under this agreement. In no event will either party be liable to the other in connection with this agreement for special, incidental, indirect or consequential or punitive damages regardless of whether either or both parties knew of the possibility of such damages.

　　一方当事人将使另一方当事人免于承担诉讼、索赔、请求、损害赔偿金及费用，包括为以下诉讼辩护而发生的合理的律师费：因另一方当事人未根据本协议履行其义务而导致损害赔偿的诉讼。

　　不管一方当事人或双方当事人是否知道特殊损害赔偿、附带损害赔偿、间接损害赔偿、后果性损害赔偿、惩罚性损害赔偿发生的可能性，一方当事人均不会为另一方当事人承担上述损害赔偿。

　　4. Contractor agrees to protect, defend, indemnify and hold harmless company, its parent, subsidiaries and affiliated companies, and its and their employees, subcontractors and its and their insurers from and against any claim, demand, cause of action, loss, expense award, obligation to indemnify another, judgment or liability on account of illness, injury or death to the employees of contractor and contractor’s subcontractors and/or damage to or loss or destruction of the property of contractor arising directly or indirectly out of the performance of this contract regardless of omissions or negligence, in whole or in any part, of company.

　　承包商同意保护、辩护、赔偿和保证公司、其上级公司、下属公司和关联公司、及其雇员、次承包商和其保险公司不承担在履行本合同过程中，不论公司是否存在部分 或全部的不作为或疏忽的责任，直接或间接所导致的承包商和次承包商的雇员生病、受伤或死亡以及承包商的财产所遭受的毁损灭失相关的任何诉求、要求、诉因、 损失、费用、对他方的赔偿义务、判决或赔偿责任。

　　II． Indemnification 条款还有多种表达方式，但并不固定。

　　1. Notwithstanding any of indemnities and liabilities specifically referred to above, neither company or contractor shall be liable to the other with respect to any consequential loss including, but not limited to, loss of anticipated profit, loss of anticipated revenue, loss of anticipated production, loss of product, or loss of use of money, arising or alleged to arise out of either company’s or contractor’s failure to property carry out its obligations hereunder or due to omissions or negligence, in whole or any part, of the part at fault, its subcontractors or vendors or the un-seaworthiness of vessel, or strict liability, and regardless of whether pre-existing the execution of the agreement.

　　除上列特别述及的赔偿和责任外，公司或承包商相互间不承担任何间接损失，包括但不限于预计的利润损失、预计的收益损失、预计的生产损失、产品损失、无法使用金钱的损失，由于或认为系因公司或承包商未能正确地履行本合同的义务或由于该违约系由于其次承包商或供应商(买方)或船舶不适航或严格责任和不论是否存在依以前协议履行原因，所导致的'部分或全部的不作为或疏忽所造成的损失。

　　2. All remedies specified herein or otherwise available shall be cumulative and in addition to any and every other remedy provided hereunder or now or hereafter available at law or in equity. No waiver or failure to act with respect to any breach or default hereunder, whether or not the other party has notice thereof, shall be deemed to be a waiver with respect to any subsequent breach or default, whether of similar or different nature.

　　依据法律或衡平法，本“协议”所述的赔偿或其它可得的赔偿应当是累积的，并在本“协议”中规定的赔偿之外，或在现在或此后可得的赔偿之外。无论对方当事人通知与否，任何与违反协议或不履行协议有关的弃权不得视为与任何后来的违反协议或不履行协议有关的弃权，无论是否性质相同或不同。

　　III．在大型合同中，Indemnification 条款往往非常复杂，以下即为。

　　Indemnification 补偿

　　(a) Each party shall indemnify and hold harmless the other party, its shareholders, directors, officers, employees, agents, designees and assignees, or any of them, from and against all losses, damages, liabilities, expenses, costs, claims, suits, demands, actions, causes of actions, proceedings, judgments, assessments, deficiencies and charges (collectively, "Damages") caused by, relating to or arising from the performance by such party in accordance with this Contract of its obligations hereunder, and Buyer shall also indemnify Seller, without limiting the foregoing, for any such item caused by, relating to or arising from (a) the programming services which are authorized for viewing sing the System, including any assertion that any such programming service involves copyright infringement, (b) any disputes between Buyer and any of its program distributors or other distributors or affiliates, (c) any disputes or claims involving the subscribers for Buyer's programming services, or (d) any assertion that Buyer has been involved in, that Buyer's conduct of subscription involves, or that Buyer's use of the System involves, any unfair competition or violations of laws, rules or regulations.

　　(ａ)每方应就其按本合同规定履行其本合同项下义务所导致的、与其有关的或由其引发的一切损失、损害、责任、支出、费用、索赔、诉讼、要求、诉讼行为、诉因、程序、判决、估定税额、欠额以及收费(合称“损害”)补偿另一方、另一方的股东、董事、管理人员、雇员、代理、被指定人、受让人或其中任何一人，使之不受损害，并且在不对上文所述予以限制的条件下，买方还应就下述各项所导致的、与其有关的或由其引发的上述任何事项补偿卖方：

　　(a)授权对viewing sing系统提供的服务；（b）买方与项目分包商、分支机构之间的纠纷；(c) 任何用户针对买方的该项目服务的纠纷或索赔；(d) 针对买方所涉该系统的不正当竞争或违法指控。

　　(b) In the event of a third-party claim, with respect to which a party’s entitled to indemnification hereunder, a party (the "Indemnified Party") shall notify the other party (the "Indemnifying Party") in writing s soon as practicable, but in no event later than ______ days after receipt of such claims. The Indemnified Party's failure to provide such noticed shall not preclude it from seeking indemnification hereunder unless such failure has materially prejudiced the Indemnifying Party's ability to defend such claim. The Indemnifying Party shall promptly defend such claim with counsel of its own choosing) and the Indemnified Party shall cooperate with the Indemnifying Party in the defense of such claim, including the settlement of the matter on the basis stipulated by the indemnifying Party (with the Indemnifying Party being responsible for all costs and expenses of such settlement).

　　(ｂ)如果第三方提出一方按本合同规定有权获得补偿的索赔请求，一方(“受补偿方”)应在实际可能的情况下尽早通知另一方(“补偿方”)，但无论如何不得迟于在收到该等请求后的第_______日。受补偿方未给予该通知并不排除其按本合同规定寻求补偿，除非未给予该通知补偿方抗辩该索赔请求的能力受到实质影响。补偿方(与其自行选择的律师一起)应及时对该索赔请求进行抗辩，而受补偿方应在对该索赔请求进行抗辩时与补偿方合作，包括按照补偿方规定的原则就该事项达成和解(补偿方承担该和解的一切费用与支出)。

　　If the Indemnifying Party within a reasonable time after notice of a claim fails to defend the Indemnified party, the Indemnified Party shall be entitled to undertake the defense, compromise or settlement of such claim at the expense of the Indemnifying arty. Upon the assumption of the defense of such claim, the Indemnifying arty may settle, compromise or defend as it sees fit. Notwithstanding anything to the contrary set forth in this Section, seller will defend any suit, claim, action or proceeding brought against buyers to the extent that such suit, claim, action or proceeding is based on a claim that goods manufactured and sold by Seller to Buyer infringe patent, copyright, mask work, trademark, trade secret or any other intellectual property rights of any third party and Seller shall pay all damages and costs awarded by final judgment (from which no appeal may be taken) against Buyer, as well as its actual expenses and costs, on condition that Seller

　　如果补偿方收到索赔通知后为受补偿方辩护，则受补偿方应有权对该索赔进行抗辩、妥协或和解，费用由补偿方承担。在承担对该等索赔请求的辩护后，补偿方可进行和解、妥协或抗辩，由其酌处。无论本条有何相反的规定，如果发生对买方的诉讼、索赔、诉讼行为或程序是基于以下主张，即卖方制造并销售给买方的物品侵犯了任何第三方的_______国专利、版权、掩模、商标、商业秘密或其他任何知识产权，则卖方将就该诉讼、索赔、诉讼行为或程序为买方辩护，并将支付局判决(不能再上诉的)判定由买方承担的损害赔偿与费用，以及买方实际的支出与费用，上述规定的条件是：

　　(i) is promptly informed and furnished a copy of ach communication, notice or other action relating to the alleged infringement, (ii) is given sole control of the defense (including the right to select counsel), and the sole right to compromise and settle such suit or proceeding; provided however, that Seller's liability hereunder, if any, shall be strictly and solely limited to the amount of royalties which would be payable in respect of revenues derived by Seller from Buyer from sales of the infringing goods. Seller shall not be obligated to defend or be liable for costs and damages if the infringement arises out if a combination with, an addition to, or modification of the goods after delivery by Seller, or from use of the goods, or any part thereof, in the practice of a process.

　　(1)卖方被及时告知侵权指控的发生，并得到与该侵权指控有关的每一通讯、通知或其他诉讼文书的副本，(2)得到该辩护的独家控制权(包括选择律师的权利)，以及就诉讼或程序进行妥协或者和解的独家权利；但是，卖方在本合同项下的责任(如果有的话)，应严格地并且仅仅限于卖方因买方销售侵权物品而应从买方获得的特许权使用费收入金额。如果侵权是由卖方交货后有人将物品混合、添加或改造而引起，或者由实施某一方法时使用物品(或其何部分)而引起，则卖方无义务进行辩护，亦无承担费用或损害赔偿的责任。

　　If any goods manufactured and supplied by Seller to Buyer are held to infringe any valid patent and Buyer is enjoined from using the same, or if seller believes such infringement is likely, Seller will exert all reasonable efforts at its option and expense (i) to procure for Buyer the right to use such goods free of any liability for such infringement, or (ii) replace or modify such goods with a noninfringing substitute otherwise complying substantially with all the requirements of this contract, or (iii) upon return of the goods, refund the purchase price and the transportation costs of such goods (less reasonable allowance for their use and benefit derived therefrom for the period of time from delivery to Buyer, such allowance being based on a straight-line depreciation period of _______ years from the date of shipment by Seller).

　　如果卖方制造并向买方提供的任何物品被判定侵犯有效的_______国专利，且卖方被禁止使用该专利，或者如果卖方相信很可能发生侵权，卖方将尽一切合理的努力，自费从以下措施中作出选择：(1)为买方取得使用该等物品而不产生侵权责任的权利，或(2)以在其他方面实质符合本合同所有规定的非侵权替代品来代替或改造该等物品，或(3)在该等物品被返还后，退还该等物品的购买价以及运费(扣除向买方交货至退还期间使用该等物品并从中获得利益的折扣金额，该折扣金额按从卖方装运之日起_______年直线式折旧来计算)。

　　If the infringement is alleged prior to completion of delivery of the goods, Seller has the right to decline to make further shipments without being in breach of contract. If Seller has not been enjoined from selling such goods to Buyer, Seller may (at Seller's sole election), at Buyer's request, supply such goods to Buyer, in which event Buyer shall be deemed to extend to Seller the same patent indemnity hereinabove stated. The same patent indemnity shall be deemed to be extended to Seller by buyer if any suit or proceeding is brought against Seller based on a claim that the goods manufactured by Seller in compliance with Buyer's specifications infringe any valid patent. Buyer shall promptly notify Seller of any infringement by a third party of intellectual property rights licensed to Buyer under this contract. In the event that a third party infringes such intellectual property rights, the Parties shall cooperate with one another to take appropriate action to cause such infringement to cease. The foregoing states the sole and exclusive liability of the parties hereto for infringement of patents, copyrights, mask works, trade secrets trademarks, and other proprietary rights, whether direct or contributory, and is in lieu of all warranties, express, implied or statutory, in regard hereto, including, without limitation, the warranty against infringement specified in the uniform commercial code.

　　如果交货完成前发生权指控，卖方有权拒绝进一步装运，而不构成违约。如果卖方还没有被禁止向买方销售该等物品，应买方请求，卖方可以(仅由卖方酌定)向买方供应该等物品，在此情况下，买方应被视为向卖方做出与本合同上文所述相同的专利补偿保证。如果有人指称卖方按照买方规格制造的物品侵犯了有效的_______国专利，并以此为根据向卖方提起诉讼或程序，则买方应被视为已向卖方做出同样的专利补偿保证。

　　买方应将第三方侵犯本合同项下许可给买方的知识产权及时通知卖方。如果第三方侵犯该等知识产权，双方应互相合作，采取适当的行动制止该侵权行为。

　　上文规定了本合同双方就专利、版权、掩模、商业秘密、商标以及其他专有权利的侵权(无论是直接的还是协从的)所承担的唯一责任，并且取代就其所做出的所有保证(明示的、暗示的或法定的)，包括(但不限于)＿＿＿＿＿中规定的不侵权保证。

英文合同 篇3

　　Address:

　　Telephone：

　　Party B: Address:

　　Telephone：

　　According to the provisions of the contract law of the People's Republic of China and the relevant laws and regulations, Party B accepts the entrustment of the first party and entrustment with the two parties through consultation.

　　First, entrustment:

　　Two, the way of payment:

　　1, Party A shall pay 40% of the total cost of the contract, namely ____ yuan (RMB) to Party B, Party B received the money after the start of design.

　　2. Party B shall provide complete design draft. After confirmation by Party A, the total amount of the total cost shall be paid.

　　Three. Design time:

　　1, Party B shall provide complete design draft in __ working days.

　　2, Party B shall complete the design work of party a company commissioned in _____ years __ month __ day (delay time by party a reason, work time should be postponed).

　　Four. The responsibilities and obligations of the two parties:

　　1, Party B shall, according to the requirements of Party A to finish the related work on time.

　　2, Party A has the responsibility to fully cooperate with Party B to carry out the work stipulated in this contract and provide relevant information according to the needs of Party B. Party A is responsible for the consequences caused by Party A's delay in the required information.

　　3. Party A shall provide complete design information before the start of the design, due to Party A's provision of incomplete information and changes in content.

　　For structural changes, Party A shall pay the corresponding cost of design changes.

　　4. After Party B receives the complete design information of Party A, it is designed to facilitate the determination of the style of Party A, and Party B begins to design the first draft after the style is determined.

　　5, Party A has the right to put forward amendments to the works designed by Party B. The first draft Party A can make a structural modification. After the first draft is determined, the structural modifications should be made. Party A shall pay the corresponding cost separately.

　　6. The consequences of the delay due to the amendment of Party A shall be borne by Party A.

　　7, due to the loss caused by post production by Party A alone, the loss caused by problems in the design of the product is borne by Party B. The legal liability caused by copyright, for the economic disputes shall be borne by Party a..

　　8. During the course of the project, Party B is attached to the brand of Party A and shall not sign any form of cooperation agreement with the customer in the identity of Party B.

　　Five. The agreement on intellectual property rights:

　　1, Party B has the copyright of the works completed by the design. After the settlement of all the fees designed by Party A, Party B may transfer the copyright of the works to Party A.

　　2. Before Party A has not paid all the cost of the design, the copyright of the works designed by Party B shall be attributed to Party B, and Party A does not have any right to the work.

　　3. Party A shall have the right to investigate the legal liability of Party A if it uses or amends the works designed by Party B before the payment is not paid.

　　Six. Liability for breach of contract:

　　1, Party A terminates the contract before the completion of the first draft of the design work. The prepaid expenses have no right to request the return. If a party terminates the contract after the completion of the first draft of Party B's work, it shall pay the full design fee.

　　2. If Party B terminates the contract without proper reasons, the fees charged shall be returned to Party A.

　　Seven, if a party or a party has a dispute over the performance of this contract, it shall be settled amicable through negotiation. If either party fails to negotiate, any Party A and B can submit it to the Beijing Arbitration Commission for arbitration.

　　Eight, the contract is effective from the date of signature by Gai Zhang and both parties. The contract is two copies in one form. Each party has one contract signed by the other party (Gai Zhang), which has the same legal effect.

　　Nine. If there is no matter in this contract, the two parties shall jointly discuss and supplement the contract. The contents of the supplement and modification are equally valid to this contract.

　　Party A: Party B:

　　(signature seal) (signature seal)

　　Date: Date:

　　中文版

　　地址：

　　电话：

　　乙方：地址：

　　电话：

　　依据《中华人民共和国合同法》和有关法规的规定，乙方接受甲方的委托，就委托设计事项，双方经协商一致，签订本合同，信守执行：

　　一、委托事项：

　　二、付款方式：

　　1、甲方需在合同签订之时支付总费用的40% ，即____元(人民币)给乙方，乙方收到甲方的款项后开始设计。

　　2、乙方提供完整的设计稿，甲方确认后,应当即付清总费用的全部余款。

　　三、设计时间：

　　1、乙方需在__个工作日内提供比较完整的设计稿。

　　2、乙方需在_____年__月__日完成甲方公司委托的设计工作 (由甲方原因耽误的时间，完稿时间应顺延)。

　　四、双方的责任与义务：

　　1、乙方应按甲方要求按质按量按时完成相关设计工作。

　　2、甲方有责任全力配合乙方开展本合同所规定的工作，并根据乙方需要提供相关资料。由于甲方提供所需资料延误时间造成的后果，由甲方承担。

　　3、甲方应在设计开始前提供完整的设计资料，由于甲方提供资料不完整、内容改动而造成的设

　　计结构改动，甲方须另行支付相应的设计改动费用。

　　4、乙方收到甲方的完整设计资料后进行部分小样设计以方便甲方确定风格，风格确定后乙方开始进行初稿设计。

　　5、甲方有权对乙方所设计的作品提出修改意见，初稿甲方可提出一次结构上的修改，初稿确定后的`结构修改，甲方须另行支付相应费用。

　　6、因甲方修改，延误时间造成的后果，由甲方承担。

　　7、由于后期制作造成的损失由甲方独自承担，由于制作物设计出现问题造成的损失由乙方承担。 因版权、文责所引发的法律责任，经济纠纷由甲方承担。

　　8、设计项目期间乙方挂靠于甲方品牌之中，不得以乙方身份单独与客户签订任何形式的合作协议。

　　五、知识产权约定：

　　1、乙方对设计完成的作品享有著作权。甲方将委托设计的所有费用结算完毕后，乙方可将作品著作权转让给甲方。

　　2、甲方在未付清所有委托设计费用之前，乙方设计的作品著作权归乙方，甲方对该作品不享有任何权利。

　　3、甲方在余款未付清之前擅自使用或者修改使用乙方设计的作品而导致的侵权，乙方有权追究其法律责任。

　　六、违约责任：

　　1、甲方在设计作品初稿完成前终止合同，其预付的费用无权要求退回；甲方在乙方作品初稿完成后终止合同的，应当支付全额的设计费用。

　　2、乙方如无正当理由提前终止合同，所收取的费用应当全部退回给甲方。

　　七、甲乙双方如因履行本合同发生纠纷，应当友好协商解决，协商不成的，甲乙双方任何一方均可向北京仲裁委员会提请仲裁解决。

　　八、本合同自甲乙双方签字盖章之日起生效，本合同一式两份，双方各持对方签字（盖章）合同一份，具有同等的法律效力。

　　九、本合同如有未尽事宜，由甲乙双方共同讨论补充或修改。补充和修改的内容与本合同具有同等效力。

　　甲方： 乙方：

　　（签字盖章） （签字盖章）

　　日期： 日期：

英文合同 篇4

　　Purchase Contract

　　合同编号(Contract No.): _______________

　　签订日期(Date) :＿＿＿＿＿＿＿＿＿＿_ 签订地点(Signed at) :＿＿＿＿＿＿＿____

　　买方：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　The Buyer:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　地址： ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　电话(Tel):___＿＿＿＿＿＿＿＿ 传真(Fax):＿＿＿＿＿＿＿＿＿＿

　　电子邮箱(E-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　卖方：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　The Seller:＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　地址：＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　Address: ＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿_＿

　　电话(Tel):_＿＿＿＿＿＿＿＿ 传真(Fax):＿＿＿＿＿＿＿＿＿＿＿

　　电子邮箱(E-mail):＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿＿

　　买卖双方同意按照下列条款签订本合同：

　　The Seller and the Buyer agree to conclude this Contract subject to the terms and conditions stated below:

　　1. 货物名称、规格和质量（Name, Specifications and Quality of Commodity）：

　　2. 数量（Quantity）：

　　允许＿＿＿＿的溢短装（＿＿＿% more or less allowed）

　　3. 单价（Unit Price）：

　　4. 总值（Total Amount）：

　　5. 交货条件(Terms of Delivery) FOB/CFR/CIF＿＿＿＿＿＿＿

　　6. 原产地国与制造商 (Country of Origin and Manufacturers):

　　7. 包装及标准（Packing）：

　　货物应具有防潮、防锈蚀、防震并适合于远洋运输的包装，由于货物包装不良而造成的货物残损、灭失应由卖方负责。卖方应在每个包装箱上用不褪色的颜色标明尺码、包装箱号码、毛重、净重及“此端向上”、“防潮”、“小心轻放”等标记。

　　The packing of the goods shall be preventive from dampness, rust, moisture, erosion and shock, and shall be suitable for ocean transportation/ multiple transportation. The Seller shall be liable for any damage and loss of the goods attributable to the inadequate or improper packing. The measurement, gross weight, net weight and the cautions such as "Do not stack up side down", "Keep away from moisture", "Handle with care" shall be stenciled on the surface of each package with fadeless pigment.

　　8. 唛头（Shipping Marks）：

　　9. 装运期限（Time of Shipment）：

　　10. 装运口岸（Port of Loading）：

　　11. 目的口岸（Port of Destination）：

　　12. 保险（Insurance）：

　　由＿＿＿＿按发票金额110%投保＿＿＿＿＿险和＿＿＿＿＿附加险。

　　Insurance shall be covered by the ________ for 110% of the invoice value against _______ Risks and __________ Additional Risks.

　　13. 付款条件（Terms of Payment）：

　　(1) 信用证方式：买方应在装运期前/合同生效后＿＿日，开出以卖方为受益人的不可撤销的议付信用证，信用证在装船完毕后＿＿日内到期。

　　Letter of Credit: The Buyer shall, ______ days prior to the time of shipment /after this Contract comes into effect, open an irrevocable Letter of Credit in favor of the Seller. The Letter of Credit shall expire ____ days after the completion of loading of the shipment as stipulated.

　　(2) 付款交单：货物发运后，卖方出具以买方为付款人的付款跟单汇票，按即期付款交单（D/P）方式，通过卖方银行及＿＿＿＿＿银行向买方转交单证，换取货物。

　　Documents against payment: After shipment, the Seller shall draw a sight bill of exchange on the Buyer and deliver the documents through Sellers bank and ______ Bank to the Buyer against payment, i.e D/P. The Buyer shall effect the payment immediately upon the first presentation of the bill(s) of exchange.

　　(3) 承兑交单：货物发运后，卖方出具以买方为付款人的付款跟单汇票，付款期限为＿＿＿＿后＿＿日，按即期承兑交单(D/A＿＿日)方式，通过卖方银行及＿＿＿＿＿＿银行，经买方承兑后，向买方转交单证，买方在汇票期限到期时支付货款。

　　Documents against Acceptance: After shipment, the Seller shall draw a sight bill of exchange, payable_____ days after the Buyers delivers the document through Seller’s bank and _________Bank to the Buyer against acceptance (D/A ___ days). The Buyer shall make the payment on date of the bill of exchange.

　　(4) 货到付款：买方在收到货物后＿＿天内将全部货款支付卖方（不适用于FOB、CRF、CIF术语）。

　　Cash on delivery (COD): The Buyer shall pay to the Seller total amount within ______ days after the receipt of the goods (This clause is not applied to the Terms of FOB, CFR, CIF).

　　14. 单据（Documents Required）：

　　卖方应将下列单据提交银行议付/托收：

　　The Seller shall present the following documents required to the bank for negotiation/collection:

　　(1) 标明通知收货人/受货代理人的全套清洁的'、已装船的、空白抬头、空白背书并注明运费已付/到付的海运/联运/陆运提单。

　　Full set of clean on board Ocean/Combined Transportation/Land Bills of Lading and blank endorsed marked freight prepaid/ to collect;

　　(2) 标有合同编号、信用证号（信用证支付条件下）及装运唛头的商业发票一式＿＿份； Signed commercial invoice in ______copies indicating Contract No., L/C No. (Terms of L/C) and shipping marks;

　　(3) 由＿＿＿＿＿＿出具的装箱或重量单一式＿＿份；

　　Packing list/weight memo in ______ copies issued by＿＿；

　　(4) 由＿＿＿＿＿＿出具的质量证明书一式＿＿份；

　　Certificate of Quality in _______ copies issued by＿＿＿＿；

　　(5) 由＿＿＿＿＿＿出具的数量证明书一式＿＿份；

　　Certificate of Quantity in ___ copies issued by＿＿＿＿；

　　(6) 保险单正本一式＿＿份(CIF 交货条件)；

　　Insurance policy/certificate in ___ copies (Terms of CIF)；

　　(7)＿＿＿＿签发的产地证一式＿＿份；

　　Certificate of Origin in ___ copies issued by＿＿＿＿；

　　(8) 装运通知(Shipping advice): 卖方应在交运后_____小时内以特快专递方式邮寄给买方上述第＿＿项单据副本一式一套。

　　The Seller shall, within ____ hours after shipment effected, send by courier each copy of the above-mentioned documents No. ＿＿.

　　15. 装运条款（Terms of Shipment）：

　　(1) FOB交货方式

　　卖方应在合同规定的装运日期前30天，以＿＿＿＿方式通知买方合同号、品名、数量、金额、包装件、毛重、尺码及装运港可装日期，以便买方安排租船/订舱。装运船只按期到达装运港后，如卖方不能按时装船，发生的空船费或滞期费由卖方负担。在货物越过船弦并脱离吊钩以前一切费用和风险由卖方负担。

　　The Seller shall, 30 days before the shipment date specified in the Contract, advise the Buyer by _______ of the Contract No., commodity, quantity, amount, packages, gross weight, measurement, and the date of shipment in order that the Buyer can charter a vessel/book shipping space. In the event of the Seller's failure to effect loading when the vessel arrives duly at the loading port, all expenses including dead freight and/or demurrage charges thus incurred shall be for the Seller's account.

　　(2) CIF或CFR交货方式

　　卖方须按时在装运期限内将货物由装运港装船至目的港。在CFR术语下，卖方应在装船前2天以＿＿＿＿方式通知买方合同号、品名、发票价值及开船日期，以便买方安排保险。

　　The Seller shall ship the goods duly within the shipping duration from the port of loading to the port of destination. Under CFR terms, the Seller shall advise the Buyer by _________ of the Contract No., commodity, invoice value and the date of dispatch two days before the shipment for the Buyer to arrange insurance in time.

　　16. 装运通知（Shipping Advice）：

　　一俟装载完毕，卖方应在＿＿小时内以＿＿＿＿方式通知买方合同编号、品名、已发运数量、发票总金额、毛重、船名/车/机号及启程日期等。

　　The Seller shall, immediately upon the completion of the loading of the goods, advise the Buyer of the Contract No., names of commodity, loading quantity, invoice values, gross weight, name of vessel and shipment date by _________ within ________hours.

　　17. 质量保证（Quality Guarantee）：

　　货物品质规格必须符合本合同及质量保证书之规定，品质保证期为货到目的港＿＿个月内。在保证期限内，因制造厂商在设计制造过程中的缺陷造成的货物损害应由卖方负责赔偿。 The Seller shall guarantee that the commodity must be in conformity with the quatity,

　　specifications and quantity specified in this Contract and Letter of Quality Guarantee. The guarantee period shall be ______ months after the arrival of the goods at the port of destination, and during the period the Seller shall be responsible for the damage due to the defects in designing and manufacturing of the manufacturer.

　　18. 检验（Inspection） （以下两项任选一项）：

　　（1）卖方须在装运前＿＿日委托＿＿＿＿＿＿检验机构对本合同之货物进行检验并出具检验证书，货到目的港后，由买方委托＿＿＿＿＿＿＿＿检验机构进行检验。

　　The Seller shall have the goods inspected by ______ days before the shipment and have the Inspection Certificate issued by____. The Buyer may have the goods reinspected by ________ after the goods?rrival at the destination.

　　(2) 发货前，制造厂应对货物的质量、规格、性能和数量/重量作精密全面的检验，出具检验证明书，并说明检验的技术数据和结论。货到目的港后，买方将申请中国商品检验局(以下简称商检局)对货物的规格和数量/重量进行检验，如发现货物残损或规格、数量与合同规定不符，除保险公司或轮船公司的责任外，买方得在货物到达目的港后＿＿日内凭商检局出具的检验证书向卖方索赔或拒收该货。在保证期内，如货物由于设计或制造上的缺陷而发生损坏或品质和性能与合同规定不符时，买方将委托中国商检局进行检验。

　　The manufacturers shall, before delivery, make a precise and comprehensive inspection of the goods with regard to its quality, specifications, performance and quantity/weight, and issue inspection certificates certifying the technical data and conclusion of the inspection. After arrival of the goods at the port of destination, the Buyer shall apply to China Commodity Inspection Bureau (hereinafter referred to as CCIB) for a further inspection as to the specifications and quantity/weight of the goods. If damages of the goods are found, or the specifications and/or quantity are not in conformity with the stipulations in this Contract, except when the responsibilities lies with Insurance Company or Shipping Company, the Buyer shall, within _____ days after arrival of the goods at the port of destination, claim against the Seller, or reject the goods according to the inspection certificate issued by CCIB. In case of damage of the goods incurred due to the design or manufacture defects and/or in case the quality and performance are not in conformity with the Contract, the Buyer shall, during the guarantee period, request CCIB to make a survey.

　　19. 索赔（Claim）：

　　买方凭其委托的检验机构出具的检验证明书向卖方提出索赔（包括换货），由此引起的全部费用应由卖方负担。若卖方收到上述索赔后______天未予答复，则认为卖方已接受买方索赔。

　　The buyer shall make a claim against the Seller (including replacement of the goods) by the further inspection certificate and all the expenses incurred therefrom shall be borne by the Seller. The claims mentioned above shall be regarded as being accepted if the Seller fail to reply within ______days after the Seller received the Buyer's claim.

　　20. 迟交货与罚款（Late delivery and Penalty）:

　　除合同第21条不可抗力原因外，如卖方不能按合同规定的时间交货，买方应同意在卖方支付罚款的条件下延期交货。罚款可由议付银行在议付货款时扣除，罚款率按每＿＿天收＿＿%，不足＿＿天时以＿＿天计算。但罚款不得超过迟交货物总价的____%。如卖方延期交货超过合同规定＿＿天时，买方有权撤销合同，此时，卖方仍应不迟延地按上述规定向买方支付罚款。

　　买方有权对因此遭受的其它损失向卖方提出索赔。

　　Should the Seller fail to make delivery on time as stipulated in the Contract, with the exception of Force Majeure causes specified in Clause 21 of this Contract, the Buyer shall agree to postpone the delivery on the condition that the Seller agree to pay a penalty which shall be deducted by the paying bank from the payment under negotiation. The rate of penalty is charged at______% for every ______ days, odd days less than _____days should be counted as ______ days. But the penalty, however, shall not exceed_______% of the total value of the goods involved in the delayed delivery. In case the Seller fail to make delivery ______ days later than the time of shipment stipulated in the Contract, the Buyer shall have the right to cancel the Contract and the Seller, in spite of the cancellation, shall nevertheless pay the aforesaid penalty to the Buyer without delay.

　　The buyer shall have the right to lodge a claim against the Seller for the losses sustained if any.

　　21. 不可抗力（Force Majeure）：

　　凡在制造或装船运输过程中，因不可抗力致使卖方不能或推迟交货时，卖方不负责任。在发生上述情况时，卖方应立即通知买方，并在＿＿天内，给买方特快专递一份由当地民间商会签发的事故证明书。在此情况下，卖方仍有责任采取一切必要措施加快交货。如事故延续＿＿天以上，买方有权撤销合同。

　　The Seller shall not be responsible for the delay of shipment or non-delivery of the goods due to Force Majeure, which might occur during the process of manufacturing or in the course of loading or transit. The Seller shall advise the Buyer immediately of the occurrence mentioned above and within_____ days thereafter the Seller shall send a notice by courier to the Buyer for their acceptance of a certificate of the accident issued by the local chamber of commerce under whose jurisdiction the accident occurs as evidence thereof. Under such circumstances the Seller, however, are still under the obligation to take all necessary measures to hasten the delivery of the goods. In case the accident lasts for more than _____ days the Buyer shall have the right to cancel the Contract.

　　22. 争议的解决 (Arbitration):

　　凡因本合同引起的或与本合同有关的任何争议应协商解决。若协商不成，应提交中国国际经济贸易仲裁委员会深圳分会，按照申请仲裁时该会现行有效的仲裁规则进行仲裁。仲裁裁决是终局的，对双方均有约束力。

　　Any dispute arising from or in connection with the Contract shall be settled through friendly negotiation. In case no settlement is reached, the dispute shall be submitted to China International Economic and Trade Arbitration Commission (CIETAC),Shenzhen Commission for arbitration in accordance with its rules in effect at the time of applying for arbitration. The arbitral award is final and binding upon both parties.

　　23. 通知（Notices):

　　所有通知用＿＿＿＿文写成，并按照如下地址用传真/电子邮件/快件送达给各方。如果地址有变更，一方应在变更后＿＿日内书面通知另一方。

　　All notice shall be written in _____ and served to both parties by fax/courier according to the following addresses. If any changes of the addresses occur, one party shall inform the other party of the change of address within ____days after the change.

　　24. 本合同使用的FOB、CFR、CIF术语系根据国际商会《20xx年国际贸易 术语解释通则》。

　　The terms FOB、CFR、CIF in the Contract are based on INCOTERMS 20xx of the

英文合同 篇5

　　ABC 服饰有限公司

　　ABC Garments & Accessories Co., Ltd

　　售货合约SALES CONTRACT

　　合同编号CONTRACT NO.ABC091102

　　日期DATE NOV. 02, 20xx

　　买方BUYER Arrabon Trading ,Unit 9, Central Office Park,

　　257 Jean Ave, Centurion

　　Tel: +357 27 664 0587 Fax: +357 27 664 0586

　　卖方SELLER ABC GARMENTS & ACCESSORIES CO., LTD

　　HONGXIN ROAD, HANGZHOU, ZHEJIANG,CHINATEL: FAX:

　　双方同意按下列条款由买方购进卖方售出下列商品:

　　The Buyers agree to buy and the Sellers agree to sell the following goods on terms and conditions as set forth below :

　　(1) 货物名称及规格,包装及装运墨头| (2) 数量 |(3) 单价| (4) 总价

　　Name of Commodity, Specifications, QuantityUnit Price Total Amount

　　boy’s denim long pant 1000PCSUSD9.50 USD9500.00 boy’s twill long pant1000PCS USD10.00 USD10000.00TOTAL: USD19500.00 SPECIFICATION AS BELOW:

　　Fabric: 100% cotton, 8 oz denim/40s40s 133/72 twill

　　Size: 9 – 36 month,Long pant with front mock(fake) fly,

　　waistband stud opening,back elastic with belt loops.

　　PACKING:

　　One polybag per pc, 10 pcs a carton-box, solid color/

　　per carton-box, 5 moisture-proofing agentper carton-box,

　　an inner-cover-cardboard per carton-box

　　MARK:

　　MAIN MARK :SIDE MARK:

　　ARRABONARRBON

　　DESRRIPTION:N.W.:

　　COLOR: G.W.:

　　QTTY :20xxPCSNO.: 1 TO UP/TOTAL CTN NOS.

　　(装运数量允许有5%的增减 Shipping QuantityFive Percent More or Less Allowed)

　　(5) 装运期限Time of Shipment50DAYS AFTER THE SELLER RECEIVE THE L/C.

　　(6) 装运口岸Port of loading SHANGHAI

　　(7) 目的口岸Port of Destination LIMASSOL, CYPRUS

　　(8) 保险投保InsuranceALL RISK AND WAR RISK COVERED BY BUYER

　　(9) 付款条件Terms of Payment IRREVOCABLE L/C AT SIGHT

　　该信用证必须在 45天 前开到卖方, 信用证的有效期应为装船期后15天, 在上述装运口岸到期,

　　否则卖方有权取消本售货合约并保留因此而发生的一切损失的索赔权 .

　　The covering Letter of Credit must reach the Sellers 45 Days Prior to the Shipment Date and is to

　　remain valid in above indicated Loading Ports 15 days after the date of shipment, failing which the Sellers reserve the right to cancel this Sales Contract and to claim from the Buyers compensation for losses resulting therefrom.

　　其他条 款 OTHER TERMS :

　　（1） 异议 : 品质异议须于货到目的口岸之日起30天内提出,数量异议须于货到目的口岸之日起15天内提出。 但均须提供经卖方同意的公证行的检验证明. 如责任属于卖方者卖方

　　于收到异议20天内答复买方并提出处理意见.

　　QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim should be filed

　　by the Buyers within 30 days after the arrival of the goods at port of destination, while for quantity discrepancy claim should be filed by the Buyers within 15 days after the arrival of the goods at

　　port of destination. In all cases, claims must be accompanied by Survey Reports of Recognized

　　Public Surveyors agreed to by the Sellers. Should the responsibility of the subject under claim

　　be found to rest on part of the Sellers, the Sellers shall, within 20 days after receipt of the claim,

　　send his reply to the Buyers together with suggestion for settlement.

　　（2） 信用证内应明确规定卖方有权可多装或少装所注名的`百分数，并按实际装运数量议付。 （信用证之金额应较本售货合约的金额增加相应的百分数）

　　The Sellers reserve the option of shipping the indicated percentage more or less than the quantity hereby contracted, and the covering Letter of Credit shall be negotiated for the amount coveringthe value of quantity actually shipped. (The Buyers are requested to establish the L/C in accordwith the indicated percentage over the total value of order as per this Sales Contract.)

　　（3） 信用证内容须严格符合本售货合约的规定，否则修改信用证的费用由买方负担，卖方亦 不负因修改信用证而延误装运的责任。并保留因此而发生的一切损失的索赔权。

　　The contents of the covering Letter of Credit shall be in strict accordance with stipulations of the Sales Contract; in case of any variation thereof necessitating amendment of the L/C, the Buyersshall bear the expenses for effecting the amendment. The sellers shall not be held responsible for possible delay of shipment resulting from awaiting the amendment of the L/C, and reserve the right to claim from the Buyers compensation for the losses resulting therefrom.

　　（4） 除经约定保险归买方投保者外，由卖方向中国的保险公司投保。如买方须增加保险额或 须加保其他险，可于装船前提出，经买方同意后代为投保，其费用由买方负担。

　　Except in case where the insurance is covered by the Buyers as arranged, insurance is to becovered by the Sellers with a Chinese insurance company. If insurance for additional amountand/or for other insurance terms is required by the Buyers, prior notice to this effect mush reach the Sellers before shipment and is subject to the Sellers’ agreement, and the extra insurance premium shall be for the Buyers’ account.

　　（5） 买方须将申请许可证副本（经有关银行副署）寄给卖方俟许可证批出后再即用传真通知 卖方，假如许可证被驳退，买方须征得卖方的同意方可重行申请许可证。

　　The Buyers are requested to send to the Sellers authentic copy of the License-application

　　(endorsed by the relative bank) filed by the Buyers and to advise the Sellers by fax immediately

　　when the said License is obtained. Should the Buyers intend to file reapplication for License

　　in cases of rejection of the original application, the Buyers shall contact the Sellers and obtain the

　　latter’s consent before filing reapplication.

　　（6） 商品检验：产地证明书或中国有关机构所签发的品质数量/重量检验证，作为品质数量/ 重量的交货依据。

　　INSPECTION : The Certificate of Origin and/or the Inspection Certification of

　　Quality/Quantity/Weight issued by the relative institute shall be taken as the basis for the shipping Quality/Quantity/Weight

　　（7） 因人力不可抗拒事故，使卖方不能在本售货合约规定期限内交货或不能交货，卖方不负 责任，但是卖方必须立即以传真通知买方，如果买方提出要求，卖方应以挂号函向买方提供由中国国际贸易促进委员会或有关机构出具的证明，证明事故的存在。买方不能领

　　到进口证不能被认为系属人力不可抗拒范围。

　　The Sellers shall not be held responsible if they owing to Force Majeure cause or causes fail to

　　make delivery within the time stipulated in this Sales contract or cannot delivery the goods.

　　However the Sellers shall inform immediately the Buyers by fax. The Sellers shall delivery to

　　the Buyers by registered letter, if it is requested by the Buyers, a certificate issued by the China

　　council for the Promotion of International Trade or by any competent authority, certifying to the

　　existence of the said cause or causes. Buyers’ failure to obtain the relative Import license is notto be treated as Force Majeure.

　　（8） 仲裁 ： 凡因执行本合约或有关本合约所发生的一切争执，双方应以友好方式协商解决，如果协商不能解决，应提交北京中国国际贸易促进委员会对外贸易仲裁委员会根据中国 国际贸易促进委员会对外贸易仲裁委员会的仲裁程序暂行规则进行仲裁，仲裁裁决是终 局的，对双方都有约束力。

　　ARBITRATION : All disputes arising in connection with the Sales Contract of the execution thereof shall be settled amicably by negotiation. In case no settlement can be reached, the case under dispute shall then be submitted for arbitration to the Foreign Trade Arbitration commission of the China Council for the Promotion of International Trade in accordance with the ProvisionalRules of Procedure of the Foreign Trade Arbitration commission of the China council for thePromotion of International Trade. The decision of the Commission shall be accepted as final andbinding upon both parties.

　　买 方卖方 THE BUYERSTHE SELLERS

　　.

英文合同 篇6

　　合同号：_________

　　no：_________

　　日期：_________

　　date：_________

　　为在平等互利的基础上发展贸易，有关方按下列条件签订本协议：

　　this agreement is entered into between the parties concerned on the basis of equality and mutual benefit to develop bussiness on terms and conditions mutually agreed upon as follows:

　　1．订约人

　　contracting parties

　　供货人（以下称甲方）：_________

　　supplier（hereinafter called “party a”）:_________

　　销售代理人（以下称乙方）：_________

　　agent（hereinafter called “party b”）:_________

　　甲方委托乙方为销售代理人，推销下列商品。

　　party a hereby appoint party b to act as his selling agent to sell the commodity mentioned below.

　　2．商品名称及数量或金额

　　commodity and quantity or amount

　　双方约定，乙方在协议有效期内， 销售不少于_________的商品。

　　it is mutually agreed that party b shall undertake to sell not less than _________ of the aforesaid commodity in the duration of this agreement。

　　3．经销地区

　　territory

　　只限在_________。

　　in _________ only.

　　4．订单的确认

　　confirmation of orders

　　本协议所规定商品的数量、价格及装运条件等，应在每笔交易中确认，其细目应在双方签订的销售协议书中作出规定。

　　the quantities， prices and shipments of the commodities stated in this agreement shall be confirmed in each transaction， the particulars of which are to be specified in the sales confirmation signed by the two parties hereto.

　　5．付款

　　payment

　　订单确认之后，乙方须按照有关确认书所规定的时间开立以甲方为受益人的保兑的、不可撤销的即期信用证。乙方开出信用证后，应立即通知甲方，以便甲方准备交货。

　　after confirmation of the order， party b shall arrange to open a confirmed， irrevocable l/c available by draft at sight in favour of party a within the time stipulated in the relevant s/c. party b shall also notify party a immediately after l/c is opened so that party a can get prepared for delivery.

　　6．佣金

　　commission

　　在本协议期满时，若乙方完成了第二款所规定的数额，甲方应按装运货物所收到的发票累计总金额付给乙方_________％的佣金。

　　upon the expiration of the agreement and party b's fullfilment of the total turnover mentioned in article 2， party a shall pay to party b _________% commission on the basis of the aggregate amount of the invoice value against the shipments effected.

　　7．市场情况报告

　　reports on market conditions

　　乙方每3个月向甲方提供一次有关当时市场情况和用户意见的详细报告。同时，乙方应随时向甲方提供其他供应商的类似商品样品及其价格、销售情况和广告资料。

　　party b shall forward once every three months to party a detailed reports on current market conditions and of consumers' comments. meanwhile， party b shall，from time to time， send to party a samples of similar commodities offered by other suppliers， together with their prices， sales information and advertising materials.

　　8．宣传广告费用

　　advertising & publicity expenses

　　在本协议有效期内，乙方在上述经销地区所作广告宣传的一切费用，由乙方自理。乙方须事先向甲方提供宣传广告的图案及文字说明，由甲方审阅同意。

　　party b shall bear all expenses for advertising and publicity within the aforementioned territory in the duration of this agreement and submit to party a all patterns and/or drawings and description for prior approval.

　　9．协议有效期

　　validity of agreement

　　本协议经双方签字后生效，有效期为_________天，自_________至_________。若一方希望延长本协议，则须在本协议期满前1个月书面通知另一方，经双方协商决定。

　　若协议一方未履行协议条款，另一方有权终止协议。

　　this agreement， after its being signed by the parties concerned， shall remain in force for _________ days from _________ to _________ if either party wishes to extend this agreement， he shall notice， in writing， the other party one month prior to its expiration. the matter shall be decided by the agreement and by consent of the parties hereto. should either party fail to implement the terms and conditions herein， the other party is entitled to terminate this agreement.

　　10．仲裁

　　arbitration

　　在履行协议过程中，如产生争议，双方应友好协商解决。若通过友好协商达不成协议，则提交中国国际贸易促进委员会对外贸易仲裁委员会，根据该会仲裁程序暂行规定进行仲裁。该委员会的决定是终局的，对双方均具有约束力。仲裁费用，除另有规定外，由败诉一方负担。

　　all disputes arising from the execution of this agreement shall be settled through friendly consultations. in case no settlement can be reached， the case in dispute shall then be submitted to the foreign trade arbitration commission of the china council for the promotion of international trade for arbitration in accordance with its provisional rules of procedure. the decision made by this commission shall be regarded as final and binding upon both parties. arbitration fees shall be borne by the losing party ，unless otherwise awarded.

　　11．其他条款

　　other terms & conditions

　　（1）甲方不得向经销地区其他买主供应本协议所规定的商品。如有询价，当转达给乙方洽办。若有买主希望从甲方直接订购，甲方可以供货，但甲方须将有关销售确认书副本寄给乙方，并按所达成交易的发票金额给予乙方_________％的佣金。

　　party a shall not supply the contracted commodity to any other buyer(s) in the above mentioned territory. direct enquiries， if any， will be referred to party b. however， should any other buyers wish to deal with party a directly， party a may do so. but party a shall send to party b a copy of sales confirmation and give party b _________% commission on the basis of the net invoice value of the transaction(s)concluded.

　　（2）若乙方在_________月内未能向甲方提供至少_________订货，甲方不承担本协议的'义务。

　　should party b fail to pass on his orders to party a in a period of _________ months for a minimum of _________， party a shall not bind himself to this agreement.

　　（3）对双方政府间的贸易，甲方有权按其政府的授权进行有关的直接贸易，而不受本协议约束。乙方不得干涉此种直接贸易，也无权向甲方提出任何补偿或佣金要求。

　　for any business transacted between governments of both parties， party a may handle such direct dealings as authorized by party a's government without binding himself to this agreement. party b shall not interfere in such direct dealings nor shall party b bring forward any demand for compensation therefrom.

　　（4）本协议受签约双方所签订的销售确认条款的制约。

　　this agreement shall be subject to the terms and conditions in the sales confirmation signed by both parties hereto.

　　12．本协议于_________年_________月_________日在_________签订，正本两份，甲乙双方各执一份。

　　this agreement is signed on _________ at _________ and is in two originals；each party holds one.

　　甲方（签字）：_________ 乙方（签字）：_________

　　party a(signature):_________ party b(signature):_________

英文合同 篇7

　　甲方(委托方)：

　　乙方(被委托方)：

　　签订地点：

　　签订日期：

　　两方经平等协商一致签订本合同，以确认各方权利与义务并共同遵守，商务咨询费合同范本。

　　一、甲方委托乙方服务事项

　　甲方因融资 万元事宜，委托乙方就融资方式、对象选择、操作办法、风险防范措施等事宜，委托乙方提供咨询服务。

　　二、乙方服务内容

　　1、帮助甲方联系或者寻找适合甲方融资需求的对象;2、对甲方拟进行的融资方案进行可行性论证;3、帮助或者代理甲方与潜在的融资对象进行初步的商业谈判或者协商;4、根据融资意向两方的具体情况，为甲方拟定融资参考方案;5、帮助或者指导甲方准备融资方案执行过程中所需的基本资料。

　　三、咨询服务费

　　就乙方提供的咨询服务，甲方向乙方支付的报酬为：甲方按实际取得融资额的 %向乙方支付服务费。服务费在融资通过审批并取得前一次性向乙方支付。

　　四、乙方服务期限

　　乙方收取甲方按本合同约定支付的服务费后，为甲方提供的服务至以下条件之一出现时止：

　　⑴ 甲方与合作对方实现成功合作，即甲方与合作对方主要合作合同签订;⑵ 甲方以书面形式通知乙方放弃融资计划;⑶ 甲方已经实际失去融资条件;⑷ 甲方三次以上放弃与乙方联系的客户进行实质性谈判，合同范本《商务咨询费合同范本》。

　　五、保密

　　为履行本合同，甲方向乙方提供的融资信息、关于主体与资信情况的`信息，经甲方特别明示为保密信息的，乙方应承担保密责任，未经甲方书面许可不得擅自向第三人提供或者泄露，但为履行本合同所必需的除外。

　　六、风险承担

　　1、乙方为履行本合同向甲方提供的所有信息、资料、方案与措施等均供甲方参考，对甲方使用后可能产生的风险不承担任何责任。2、乙方对帮助或者指导甲方所取得的合作对方的调查资料的真实性，对合作对象资信状况与承担责任的能力不作任何保证。3、乙方对所提供咨询服务是否能使甲方实现拟融资目的不作任何保证，甲方支付费用后，不得以任何理由要求乙方全部或者部分返还。4、对甲方与合作对方之间的合作合同的履行，乙方不承担任何责任。

　　七、违约责任

　　1、甲方逾期支付费用的，乙方有权在收到费用前暂停履行本合同约定义务。2、甲方逾期支付服务费的，应按逾期支付金额每日千分之二向乙方支付违约金。3、乙方收到甲方费用后拒不提供本合同约定服务的，应全额退还甲方已支付服务费。

　　八、争议解决方式

　　因履行本合同发生争议两方不能协商解决时，任何一方认为需通过诉讼方式解决的，由乙方所在地人民法院管辖。

　　十、其他

　　1、对本合同的修改需以书面方式进行，并且签名代表人及印章应与本合同签名与印章相符。2、本合同一式贰份，两方可执一份具有同等法律效力。3、本合同经两方签章生效。

　　本合同签订于 年 月 日

　　甲方：

　　代表人：

　　日期：

　　乙方：

　　代表人：

　　日期：

英文合同 篇8

　　Commercial Contract

　　商业合同

　　No：

　　合同号：

　　Date：

　　日 期：

　　The Buyer： Zhonghua International Technology Corporation

　　卖方：菲尔德·埃米森公司

　　The Seller： Field Emission Corp.

　　买方：中华国际技术开发公司

　　This contract is made by and between the Buyer and the Seller， whereby the Buyer agrees to buy and the Seller agrees to sell the under-mentioned commodity according to the terms and conditions stated below：

　　根据本合同条款，买方同意购买，卖方同意出售下述货品，兹签订本合同。

　　1. Commodity： camera-control equipment

　　1、品名：摄像机控制设备

　　Quantity： 60 （sets）

　　数量：60（台）

　　Unit price： USD4 800.00

　　单价：4 800美元/台

　　Total amount： USD288 000.00

　　总额：288 000美元

　　2. Country of origin and manufacturer： Field Emission Corp. in US

　　2、原产国别及生产商：美国菲尔德·埃米森公司

　　3. Packing

　　3、包装

　　To be packed in strong wooden cases or cartons， suitable for long distance ocean， parcel post or air freight transportation as well as changing climate and with good resistance to moisture and shocks.

　　用坚固的木箱或纸箱包装，适宜长途海运、邮寄或空运及适应气候变化，并且具备良好的防潮抗震能力。

　　The Seller shall be liable for any damage of the commodity due to improper packing and for any rust attributable to inadequate protective measures in regard to the packing.

　　由于包装不当而引起的货物损坏或由于防护措施不善而引起货物锈蚀，卖方应赔偿由此而造成的全部损失费用。

　　One full set of service and operation manual shall be enclosed in each case.

　　包装箱内应附有完整的维修保养、操作使用说明书。

　　4. Shipping mark：

　　4、运输标志

　　The Seller shall mark on each package with fadeless paint the package number， gross weight， net weight， measurement and warnings such as “HANDLE WITH CARE”， “KEEP AWAY FROM HEAT”， “KEEP AWAY FROM MOISTURE” as well as shipping mark.

　　卖方应在每个货箱上用不褪色油漆标明箱号、毛重、净重、长、宽、高，并标有“小心轻放”，“防潮”及“防热”等字样和运输标志。

　　5. Date of shipment： Aug. 8， 20xx

　　5、装运日期：20xx年8月8日

　　6. Port of shipment： Los Angeles

　　6、装运港：洛杉矶

　　7. Port of destination： Ningbo

　　7、目的港：宁波

　　8. Insurance：

　　8、保险

　　To be borne by the Buyer after shipment.

　　装运后由买方投保。

　　9. Payment， under conditions （1）， （2） and （3） below：

　　9、支付条件 分以下三种条件支付：

　　（1） Through the letter of credit：

　　（1）信用证

　　The Buyer， on receipt from the Seller of the delivery advice， shall open an irrevocable letter of credit with the Bank of China， in favor of the Seller for the total value of shipment 25 – 30 days prior to the date of delivery. The credit shall be available against Seller‘s draft drawn at sight on the opening bank for 100% invoice value accompanied by the shipping documents specified in Clause 10 hereof. Payment shall be effected by the opening bank by telegraphic transfer against presentation of the aforesaid draft and documents. The letter of credit shall be valid until the 20th day after the shipment is effected.

　　买方收到卖方交货通知，应在交货日期前25 – 30 天，由中国银行开出以卖方为受益人的与装运金额相同的不可撤销的信用证。卖方须向开证行出具100％发票金额即期汇票并附本合同第10款所规定的装运单据。开证行收到上述汇票和装运单据即予以电汇支付。信用证于装运日期后20天内有效。

　　（2） Collection：

　　（2）托收

　　The Seller may present the sight draft together with the shipping documents （specified in Clause 10 hereof） through the Seller‘s bank and Buyer’s Bank to the Buyer for collection after shipment.

　　货物装运后， 卖方出具即期汇票，连同本合同第10款规定的.装运单据，通过卖方所在地银行和买方银行提交给买方托收。

　　（3） By direct remittance：

　　（3）直接付款

　　Payment shall be effected by the Buyer， by telegraphic transfer， within 7 （seven） days after receipt from the Seller of the shipping documents specified in the Clause 10 hereof.

　　买方收到本合同第10款规定的装运单据后7天内， 以电汇向卖方支付货款。

　　10. Documents：

　　10、单据

　　（1） In case of sea-freight：

　　（1）海运

　　Full set of clean bills of lading marked “Freight to Collect”， “Freight Prepaid” made out to bank endorsed notifying Zhonghua International Technology Development Corporation at the port of destination.

　　全套清洁海运提单，标明“运费付讫”，“运费预付”，做成空白背书并注明通知目的港的中华国际技术开发公司。

　　（2） In case of air-freight：

　　（2） 空运

　　One copy of airway bill marked “Freight to Collect”， Freight Prepaid“ and sent to the Buyer.

　　空运提单副本一份，标明“运费付讫”，“运费预付”，寄交买方。

　　（3） Invoice in 4 copies indicating contract number and shipping mark， made out in details as per the contract concerned.

　　（3）发票一式4份，标明合同号和装运标志，发票根据有关合同详细填写。

　　（4） Packing list in 2 copies issued by the manufacturer.

　　（4）由生产商出具的装箱单一式两份。

　　（5） Certificate of quality and quantity issued by the manufacturer.

　　（5）由生产商出具的质量和数量保证书。

　　（6） The Buyer shall be advised by mail/cable immediately after shipment.

　　（6）货物装运后立即用电报或信件通知买方。

　　In addition， the Seller shall， within 10 （ten） days after shipment， send by airmail two sets of aforesaid documents （except item 4） with one set directly to the Buyer and one set directly to Zhonghua International Technology Development Corporation at the port of destination.

　　此外，发货10天内，卖方将上述单据（第5条除外）航寄两份，一份直接给买方，一份直接给目的港的中华国际开发公司。

　　11. Shipment

　　11、装运

　　（1） In case of FOB terms

　　（1） 离岸价格条款（FOB条款）

　　a. The Seller shall， 30days before the contracted date of shipment， advise the Buyer by cable or letter of the contract number， name of commodity， quality， value， package number， gross weight， measurement and date of readiness at the port of shipment for the Buyer to book shipping space.

　　1）卖方于合同规定的装运日期前30天，用电汇或信件将合同号、品名、数量、价值、箱号、毛重、装箱尺寸和货物抵装运港日期通知买方，以便买方租船订舱。

　　b. Booking of shipping space shall be arranged by the Buyer‘s shipping agent， China Ocean Shipping Agency.

　　2）买方船运代理中国外轮代理公司，负责办理租船订舱事宜。

　　c. The Buyer‘s shipping agent （China Ocean Shipping Agency） shall send to the Seller notice indicating the name of vessel， estimated date of loading and contract number for the Seller to arrange shipment 10 （ten） days before the estimated date of arrival of the vessel at the loading port. The Seller is requested to get in close contract with the shipping agent. When it becomes necessary to change the carrying vessel or to advance or delay the arrival date， the Buyer or the shipping agent shall advise the Seller in time. Should the vessel fail to arrive at the loading port within 30 （thirty） days after the arrival date advised by the Buyer， the Buyer shall bear the storage and insurance expenses incurred from the 30 day thereafter.

　　3）买方船运代理（中国外轮代理公司）预计船抵达装运港10天之前，将船名、预计装货日期、合同号等通知卖方，以便卖方安排装运。要求卖方与船运代理保持密切联系。当需要更换承运船只及船只提前、推迟抵达时，买方或其船运代理应及时通知卖方。如船在买方通知日后30天内未能到达，则第30天后仓储费和保险费用由买方承担。

　　d. The Seller shall be liable for any dead freight or demurrage， should it happen that they have failed to have the commodity ready for loading after the carrying vessel has arrived at the port of shipment on time.

　　4）如承运船如期抵达装运港，卖方因备货未妥而影响装船，则空舱费和滞期费均由卖方承担。

　　e. The Seller shall bear all expenses and risks before the commodity passes over the vessel‘s rail and is released from the tackle. After it has passed over the vessel’s rail and is released from the tackle， all expenses and risks shall be in Buyer‘s account. 5）货物超过船舷并从吊钩卸下前，一切费用和风险由卖方承担；货物超过船舷并从吊钩卸下，一切费用和风险由买方承担。

　　（2） In case of CFR terms

　　（2）成本加运费价条款（CFR条款）

　　a. The Seller shall ship the goods within the shipment time from the loading port to the port of destination. Transshipment is not allowed.

　　1） 在装运期内，卖方负责将货物从装运港装运至目的港。不得转船。

　　b. In case the goods are to be dispatched by air freight， the Seller shall， 30 （thirty） days before the time of delivery as stipulated in Clause 5， inform the Buyer by cable or letter of the estimated date of delivery， contract number， name of commodity， and invoiced value. The Seller shall， immediately after dispatch of the goods， advise the Buyer by cable or letter of the contract number， name of commodity， invoiced value and date of dispatch for the Buyer to arrange the insurance in time.

　　2） 货物空运时，卖方于本合同第5条规定的交货日期前30天，以电报或信件把预计交货期合同号、品名、发票金额等通知买方。发货后，卖方立即以电报或信件将合同号、品名、发票金额、发货日期通知买方，以便买方及时投保。

　　12. Shipping advice

　　12、装运通知

　　The Seller shall， immediately on the completion of the loading of the goods， advise the Buyer by cable or letter of the contract number， name of commodity， quantity， invoiced value， gross weight， name of vessel and date of sailing. In case the Buyer fails to arrange insurance in time due to the Seller‘s not having cabled in time， all losses shall be borne by the Seller.

　　货物一俟全部装船，卖方应即将合同号、吕名、数量、发票金额、毛重、船名及启航日期用电报或信件通知买方。如因卖方未能及时通知致使买方不能及时投保，卖方则承担全部损失。

　　13. Guarantee of quality

　　13、质量保证

　　The Seller guarantees that the commodity hereof is made of the best materials with first class workmanship， brand new， unused， and complies with the quality and specifications stipulated in this contract. The guarantee period shall be 12 （twelve） months staring from the date on which the commodity arrives at the port of destination.

　　卖方保证：所供货物由最好的材料及精湛工艺制成，商标为新的和未经使用的，其质量和规格符合本合同所做的说明。自货物到达目的港起12个月为质量保证期。

　　14. Claims

　　14、索赔

　　Except those claims for which the insurance company or the owners of the vessel are liable， should the quality， specifications or quantity be found not in conformity with the stipulations of the contract， within 90 （ninety） days after the arrival of the goods at destination， the Buyer can use the Inspection Certificate issued by China National Import and Export Commodities Inspection Corporation to claim for replacement as compensation. All the expenses incurred （such as inspection charges， freight charges for returning and sending of replacement， insurance premium， storage， loading and unloading charges） shall be borne by the Seller.

　　自货物到达目的港起90天内，如发现货物质量、规格、数量与合同规定不符，除那些应由保险公司或由船方承担的部分外，买方可凭中国进出口商品检验总公司出具的商检证书，有权要求更换或索赔。

　　In regard to quality， the Seller shall guarantee that if， within 12 （twelve） from the date of arrival of the goods at destination， damages occur in the course of operation by reason of inferior quality of material or bad workmanship， the Buyer shall immediately notify the Seller in writing and put forward a certificate issued by the CCIC. The certificate so issued shall be accepted as the base of the claim. The Seller， in accordance with the Buyer‘s claim， shall be responsible for the immediate elimination of the defects， complete or partial replacement of the commodity， or devaluate the commodity according to the state of defects. Where necessary， the Buyer may eliminate the defects themselves at the Seller’s expenses. If the Seller fails to reply within on month after receipt of the aforesaid claim， the claim shall be reckoned as having been accepted by the Seller.

　　卖方保证，货物到达目的港12个 月内，如果使用过程中由于材料质量低劣和工艺不佳而出现的损坏，买方立即以书面形式通知卖方并出具中国进出口商品检验总公司开列的检验证书，提出索赔。商 检证书为索赔的依据。按买方索赔要求，卖方有责任立即排除货物的缺陷、全部或部分更换或根据缺陷情况将货物作降价处理。

　　15. Force Majeure

　　15、不可抗力

　　The Seller shall not be held responsible for delay in shipment or non-delivery of the goods due to Force Majeure， which might occur during the process of manufacturing or in the course of loading. The Seller shall advise the Buyer of the occurrence mentioned above within 15 （fifteen） days and send by airmail a certificate of the incident issued by the local government to the Buyer. Even in such cases， the Seller is still liable to take all possible measures to expedite the delivery of goods.

　　在货物制造和装运过程中，由于发生不可抗力事故致使延期交货或不能交货，卖方概不负责。卖方在不可抗力事件发生后，应立即通知买方并在事发14天内，将事故发生所在地当局签发的证书航空邮寄给买方以作证据。即使在此情况下，卖方仍有责任采取必要的措施，尽快交货。

　　Should the Seller fails to perform the contracted obligations 10 （ten） weeks after the aforesaid incident， the Buyer shall have the right to treat the contract as null and void.

　　不可抗力事故发生后超过10个星期而合同尚未履行完毕，买方有权撤销合同。

　　16. Late delivery and penalty

　　16、合同延期和罚款

　　Should the Seller fail to make delivery within the contracted period for reasons other than Force Majeure specified in Clause 15 hereof， the Buyer may accept the postponement on condition that the Seller agrees to pay a penalty which shall be deducted by the paying bank from the agreed amount of payment. The penalty， however， shall not exceed 5% （five percent） of the total value of the goods involved in the late delivery. The rate of penalty is charged at 0.55（zero point five percent） for every seven days， odd days less than seven days should be counted as seven days. In case the Seller fails to make delivery ten weeks later than the shipment stipulated in the contract， the Buyer shall have the right to cancel the contract. The Seller， in spite of the cancellation， shall still pay the aforesaid penalty to the Buyer without delay.

　　除本合同第15条所述不可抗力原因外，卖方如不能按合同规定如期交货，并同意支付罚金，买方可同意延期交货，付款银行相应减少议定的支付金额，但罚款不得超过迟交货物总额的5％。卖方如逾期10个星期仍不能交货，买方有权撤销本合同。尽管合同已撤销，但卖方仍应如期支付上述罚金。

　　17. Arbitration

　　17、仲裁

　　All deputes in connection with this contract or the execution thereof shall be settled through friendly consultations. Should no settlement be reached， the case may then be submitted for arbitration to the Foreign Economic and Trade Arbitration Commission of the CCPIT in accordance with the rules and procedures of the said Arbitration Commission. The arbitration shall take place in 15 （fifteen） days. The decision of the Arbitration Commission shall be final and binding on both Parties. The arbitration fee shall be borne by the losing Party. The arbitration may also be settled in a third country mutually agreed upon by both Parties.

　　凡与本合同有关或因执行本合同而发生的一切纠纷，应通过友好协商解决，如果协商不能解决，则可提交中国国际贸易促进委员会对外经济贸易仲裁委员会并根据该会仲裁法则和程序进行仲裁。仲裁将在15天内进行，仲裁裁决为最终裁决，对双方都有约束力。仲裁费用由败诉方承担。仲裁也可在双方都能接受的第三国进行。

　　18. Special provisions

　　18、附加条款

　　In witness thereof， this contract is signed by both Parties in two original copies； each Party shall keep one copy.

　　本合同一式两份，双方签字划押，各执一份，特此证明。

　　The Buyer： Zhonghua International Technology Corporation

　　买方：中华国际技术开发公司

　　The Seller： Field Emission Corp.

　　卖方：菲尔德·埃米森公司

【英文合同】相关文章：

英文购销合同05-04

借款合同英文04-28

英文合同范文03-13

英文翻译合同02-28

设备采购合同英文05-10

英文购销合同模板05-04

关于借款合同英文04-29

精选英文合同三篇12-25

精选英文合同四篇02-03

英文合同必备词汇03-19